Terms of Service

By accessing or using our website, you confirm that you are at least 18 years of age and agree to comply with these Terms of Service. If you do not agree, please do not use this website.

This website is provided for informational purposes about our construction services. You agree to:

• Use this website only for lawful purposes
• Not attempt to gain unauthorised access to any part of the website
• Not transmit any harmful, offensive, or misleading content through our contact form
• Not reproduce or distribute our content without written permission

A.V. Paramashivan & Sathyam Builders provides civil construction, renovation, interior design, and project management services across Karnataka.

Submitting an enquiry through our contact form or by phone does not create a binding contract. All project engagements are formalised through a signed contract that outlines specific scope, timelines, and costs.

Any estimates or indicative costs provided on this website or in initial discussions are for guidance only and are subject to:

• A formal site inspection and assessment
• Current material and labour market rates at the time of the project
• Any changes in project scope requested by the client

Final pricing is confirmed in the signed project contract.

Payment schedules, milestone-based disbursements, and penalties for delayed payments are defined in each individual project contract. General terms include:

• An advance payment may be required before work commences
• Progress payments are typically tied to project milestones
• Final payment is due upon project completion and handover

[Specific payment terms are set out in each project contract.]

All content on this website — including text, images, logos, project photos, and design — is the intellectual property of A.V. Paramashivan & Sathyam Builders unless otherwise stated. You may not reproduce, copy, or distribute any content without our prior written consent.

Any changes to agreed project scope must be documented in a written variation order signed by both parties. Variations may affect project cost and timeline. We are not liable for delays or cost increases arising from undocumented scope changes.

We stand behind our work. Specific defects liability periods and warranty terms are outlined in each project contract. In general:

• Structural defects arising from our workmanship will be rectified at no charge within the defects liability period
• Defects arising from client-supplied materials or third-party works are excluded
• Normal wear and tear is not covered

To the fullest extent permitted by law, A.V. Paramashivan & Sathyam Builders shall not be liable for any indirect, incidental, or consequential damages arising from:

• Use of or reliance on information on this website
• Delays caused by factors outside our reasonable control (force majeure)
• Third-party contractor or supplier failures

[Maximum liability caps are specified in individual project contracts.]

We aim to resolve any disputes amicably. If a dispute cannot be resolved through direct negotiation within 30 days, both parties agree to submit to arbitration or the jurisdiction of competent courts in Bengaluru, Karnataka, India.

These Terms of Service are governed by and construed in accordance with the laws of India and the state of Karnataka.

We may update these Terms from time to time. The revised terms will be posted on this page with an updated date. Continued use of our website after any changes constitutes acceptance of the new terms.

For questions about these Terms of Service, please contact us: